《机械设备安装总承包合同通用条款中英文对照全套.docx》由会员分享,可在线阅读,更多相关《机械设备安装总承包合同通用条款中英文对照全套.docx(12页珍藏版)》请在优知文库上搜索。
1、机械设备安装总承包合同通用条款中英文对照全套GENERALCONDITIONSOFMECHANICAL,EQUIPMENT,PIPING,ELECTRICALANDINSTRUMENTATIONINSTALLATIONCONTRACT机械设备安装总承包合同通用条款(中英文对照)CONTENTS目录(部分)1. Definitions定义2. Co-operationofContract,SpecificationsandDrawings合同、规范和图纸的关系3. ContractorsFamiliaritywithConditionsofContract3.承包商对合同条件的熟悉程度9. Am
2、ountofErectionWork安装工作量10. VariationsandExtraWork工作变更和额外工作11. TenderDrawings招标图纸12. FinalDrawings,SpecificationsandEquipmentLists最终的图纸、规范和设备清单13. InaccuracyofDrawings,SpecificationsandContract关于图纸、规范和合同的错误14. ContractorsEquipment承包商的设备23. SublettingofErectionWork安装工程的分包24. DeterminationofQuantities工
3、程量的确定32.RemovalofRejectedWorkorMaterial移除被拒绝的工程或材料35.WorkandMaterialatRiskoftheContractor由承包商承担风险的工作和材料40. Order,ProgressandCompletionofErectionWork安装工作的次序、进度和竣工41. DelaysandLiquidatedDamages延误和违约金57. As-builtDrawings竣工图纸58. ContractorsReportSubmissionstoCustomer58.承包商向业主提交的报告60.SettlementofDisputes
4、-Arbitration争议解决-仲裁62. Communication通信63. 1.anguage语言部分章节示例如下:TheActualCompletionDateforErectionshallbefollowedbyCommissioningofthePlantzwhichmeansallthetestsandadjustments,whichcanbecarriedoutwithoutactualproductionofthePlant.Thisincludesthoroughcleaningandmechanical,electricalandinstrumentoperatin
5、gtestsaswellaswaterrunsandrunningofthePlantwiththeactualproductionmaterials.实际安装竣工日之后即为工厂设备的试运行,即管道无需实际生产而进行的所有检测和调试工作。这包括彻底的清洁和机械、电气和仪表的运行测试,以及试供水和用实际生产原料进行的工厂设备试运行。ConstructionManagersInstruction(CMI)nShallmeanawritteninstructionfromtheCustomertotheContractorrequiringtheContractortocarryouttheWork
6、specifiedtherein.施工经理的指令(CMI)应指由业主向承包商发出的书面指令,要求承包商执行该指令中规定的工作。2. COOPERATIONOFCONTRACT,SPECIFICATIONSANDDRAWINGS2.合同、规范和图纸的关系ThedocumentsconstitutingthisContractincludingtheSpecificationsandthedrawingsincludedhereinshallbeconsideredascomplementary,andmaterialsandworkcalledforbyoneormoreandnotmentio
7、nedbytheothersaretobefurnishedanddoneinasfaithfulandefficientamannerasiffullydealtwithinall.组成本合同的文件(包括本合同包含的规范和图纸)应被视为补充性的;由一个或多个文件所要求但其它文件未要求的材料和工作应被视为所有文件的要求,并应被尽职高效地提供和完成。3. contractor,SfamiliaritywithconditionsofCONTRACT3.承包商对合同条款的熟悉程度3.1 TheContractordeclaresthathehasfullknowledgeoftheTermsand
8、ConditionsofthisContract,andhasfullyinformedhimselfastoconditions,localandotherwise,affectingthecarryingoutofthisContract.1.1 承包商声明其完全了解本合同的条款和条件,并已充分地熟悉了影响合同履行的、当地或其他地方的条件。5. SCOPEOFWORK5.工作范围TheErectiontobecarriedoutbytheContractorshallbeallasdefinedinthisContract.TheContractorshallprovideandsuppl
9、yanddoanythingthat,intheopinionofCustomerzmayberequiredfortheexecutionoftheErectionwhetherthesamemayormaynotbeshownontheContractand/ordrawingsorparticularlydescribedintheSpecificationsprovidedthesameistobeinferredtherefrom.承包商所从事的安装应完全按照本合同的规定执行。承包商应提供、供应和实施任何业主认为执行安装需要的物品和工作,无论其是否在合同和/或图纸上表明或明确地在规范
10、中描述,但应从合同、图纸或规范中可以推断出来。6. EXAMINATIONOFMILLSITEANDMILL6.对工厂现场和工厂的检查6.1 TheContractordeclaresthathehascarefullyexaminedtheMill,theMillSiteandsurroundingareasoftheMillwithservicesandfacilitiesandisfullyawareofrelevantsiteconditionsaffectingtheexecutionoftheErection.TheContractPricehasincludedallthecos
11、tsandexpensesthatmaybeincurredbytheContractor.6.2 承包商声明其已仔细检查过工厂、工厂现场和有关服务与设施的工厂邻近地区,并且他已完全知晓了有关影响安装执行的场地条件,合同价格已涵盖了承包商所有可能的成本和费用的支出。9.AMOUNTOFERECTIONWORK9.安装工程的数量TheCustomerdoesnotzexpresslyorbyimplication,guaranteethattheactualamountsoftheErectionWorkormaterialofanyclasswillcorrespondtotheSpecifi
12、ca-tionsanddrawingsherewith.TheCustomerreservestherighttoincreaseordecreasetheamountsofanyclassorportionoftheErectionWorkasmayinhisopinionbenecessary.TheContractorshallmakenoclaimforanticipatedprofits,forlossofprofits,fordamagesorotherwise,becauseofanydifferencebetweentheamountsofErectionWorkactuall
13、ydoneormaterialsfurnishedandtheestimatedamountassetforthinthisContract.TheContractorshallbearanycostsinrelationtoprovidingextraErectionWorkormaterial,andnoclaimcanbemadeagainsttheContractorfortheextracosts.业主(明示或暗示地)不保证安装工作或任何一类材料的实际数量将与本合同所附的规范和图纸一致。业主保留在其认为必要时增加或减少任何一类或一部分安装工程的数量的权利。承包商不得因实际完成的安装工
14、作或提供的材料的数量与按本合同规定预计的数量之间存在任何差异而就预期利润、利润损失、遭受的损害或其它事项提出任何索赔。承包商应承担任何与该等额外安装工程或材料有关的任何费用,不得向业主主张该等额外费用。11TENDERDRAWINGS11.招标图纸TheContractoragreeswiththeCustomerthatthedrawingsincludedhereinanduponwhichtendersandlumpsumpricesarebasedareinsufficientdetailtoindicatetheclass,complexityandtheamountofthewor
15、kbutshallnotbeacceptedbytheContractorasfinaldrawingsoftheErectionWorktobecarriedout.承包商与业主一致同意本合同中所附的、且作为投标和总价基础的图纸已足够详细地表明了工作的类别、复杂程度和工作量,但承包商不能把它视为将要执行的安装工作的最终图纸。14.CONTRACTORSEQUIPMENT14.承包商的设备TheContractorshallsupplyandprovideallequipmentrequiredduringtheperformanceoftheContractandinconnectionwi
16、thExtraWorkassetforthherein.SuchequipmentandtheContractorsworkmethodsandorganisationforhandlingtheErectionWorkshallbesuchastosecureasatisfactoryqualityoftheErectionWorkandarateofprogresswhichintheopinionofCustomerwillensurethecompletionofthevariousitemsofErectionWorkinaccordancewiththetimeschedule.承包商供应和提供履行合同期间所需的以及与本合同规定额外工作相关的所有设备。该设备以及承包商的工作方法和管理安装工作的组织机构